Recent Updates
January 19, 2012
Changes to the AIA Performance and Payment Bonds
November 29, 2011
Design Professional Service Corporation
November 14, 2011
No Damages for Delay Provision Saves Contractor's Delay Claim from Notice of Claim Provision
October 28, 2011
Pitfalls in Arbitration and Construction Lien Enforcement
October 04, 2011
Deductibles and Self-Insured Retention on Professional Liability Policies: What Owners Need to Know
Archives
Recent GTH Decision - Construction Delay Claims
No Damages for Delay Provision Saves Contractor's Delay Claim from Notice of Claim Provision
Posted by: Richard J. Lambert
November 14, 2011
In Huen New York, Inc. v. Board of Education Clinton Central School District, Supreme Court, County of Oneida, Index No. CA2005-001680, Greenberg, Trager & Herbst, LLP represented Huen New York, Inc. ("Huen"), the prime contractor for the electrical work on a large new construction project for the School District, which was to be completed in two phases ("Project"). Huen's work on the Project was scheduled to be completed in January 2003, but was actually completed in September 2004. Thereafter, Huen brought a claim against the School District for delay damages.
